民用工程合同书VIP专享

民用工程合同书table of contents 1. scope of work 2. contract documents 3. performance security 4. value of work and completion time 5. assignment and sub letting 6. drawings 7. general obligations 8. completion of works 9. insurance of works 10. damage to persons and property 11. third party insurance 12. accident or injury to persons 13. remedy on contractor's failure to insure 14. compliance with status and regulations ，etc. 15. access to other contractors 16. contractor to keep site clean 17. labor 18. materials and workmanship 19. inspection of operations 20. removal of improper work and materials 21. suspension of work 22. commencement time and time for completion 23. extension of time for completion 24. rate of progress 25. liquidated damages for delay 26. certification of completion of work 27. guarantee against defects and liability for defective work 28. alterations， additions and omissions 29. adjustment of contract price due to variations in quantities 30. plant， temporary works and materials 31. measurement of quantities 32. provisional sums 33. payment and retention 34. remedies and power on default by contractor 35. special risks 36. frustration and payments thereof 37. settlement of disputes arbitration 38. notice 39. default of employer 40. language 41. laws to be observed no.:_________ this contract is made at_________， chesiville，parcheesi on_________month_________a.d._________between_________represented by_________， hereinafter called theemployerand_________ registeredas a juristic person in_________ （ country. ） with head office located at_________represented by_________who has been authorized to sign commitment binding on the saidjuristic person， hereinafter called the contractor. both parties...